![HT-2020-000448 - [2024] EWHC 1185 (TCC)](https://backend.juristeca.com/files/emisores/logo_yJUntHA.png){kind=logo}
The Basics Portal
The Basics Portal
DBS’s pleaded case is that the Basics Portal designed by TCS was rejected by DBS because of its inadequate quality, and because it did not comply with GDS standards, including DbD. Following the rejection of the Basics Portal, DBS aver that Mr Charles of IBM suggested that DBS would be able to develop GDS-compliant screens itself. A prototype was built by DBS with the assistance of GDS and presented to TCS, but DBS allege that TCS declined to change the work it had done on the Basics Portal. It is then pleaded that as a result of these issues, DBS decided to remove the Basics Portal from TCS’s scope of work and to design the Basics Portal itself. The Basics Portal designed by TCS has never been used.
Neither expert was in a position to evaluate the Basics Portal itself because neither had seen it. All Dr Hunt saw and evaluated was the list of useability issues that were identified by DBS, by IBM and by GDS at the time.
The issues identified by IBM related to a review carried out seemingly informally in August 2016. Mr Craven of IBM emailed Ms Keenaghan of DBS stating, ‘I went through the prototype pages earlier this week and noted a few bits down. Not sure if they will be useful for the heuristic review or not’. The attached PDF attached 7 pages of screenshots with around 12 comments in red, such as the following:
- Heading
- CONTENTS
- IntroductiON
- The Factual Witnesses
- Expert Evidence
- Programming Experts
- Forensic Accounts
- The Parties Submissions
- Principles Applicable to Issues of Construction
- The Defendant’s Obligations and Responsibilities
- Clause 15
- Clause 9.5 which states
- Clause 14.5 of Schedule 2-6 which states
- The Delay and Notice Provisions
- Clause 7
- Conditions Precedent: Clauses 5 and 6
- Conditions Precedent: the authorities
- Clause 5.6
- Clause 6
- Clause 8
- Limitations of Liability
- A single or multiple caps?
- The Delay Damages cap under Clause 52.2.5
- Is TCS’s claim for loss of anticipated costs savings excluded by Clause 52?
- Compliance with Clause 5.3, Agreement and Estoppel Introduction
- Express Agreement
- Estoppel
- Introduction
- R1 B&B Delays
- Mr Britton’s First Analysis
- Mr Britton’s Second Analysis
- Conclusion on Mr Britton’s Analyses
- TCS’s submission based upon Mr Jardine’s analysis
- Responsibilities for Delay on the ‘Infrastructure’ Critical Path
- R1-D
- Compliance with Notice Provisions
- Analysis of Delays
- Up to August 2017
- From August 2017 to 19 September 2018
- Analysis
- Failed to confirm its desired functional scope of R1 Disclosure in relation to the Customer-to-Business portal and Accountable Officer’s Update Service functionality. Such confirmation was a prerequis
- Failed to make available an end-to-end test environment for the Interactive Voice Response system
- Failed to agree upon a data migration approach, without which the Claimant could not complete the build of a data migration environment so that anonymised data could be made available for testing
- Failed to ensure that relevant external stakeholders were available to participate in Final Systems Integration Testing
- Partial Termination
- TCS’s Claims
- Non-Manpower Costs
- Anticipated Cost Savings
- Summary of TCS’s Delay Claim Recovery
- DBS’s Claims
- Delay Payments
- R1-B&B Delay
- Disclosure Scotland Extension Costs – Item 1 of the Updated Schedule of Loss
- Loss of Anticipated Savings – Item 3 of the Updated Schedule of Loss
- R1-D Delay
- R0 Licence Costs – Item 4 of the Updated Schedule of Loss
- R0 Hosting and Infrastructure Costs - Item 5 of the Updated Schedule of Loss
- R0 Technology Refresh – Item 6 of the Updated Schedule of Loss
- R0 N-1 Sustainment Costs – Item 7 of the Updated Schedule of Loss
- R0 Maintenance Costs – Item 8 of the Updated Schedule of Loss
- Savings
- Introduction
- Quality-related Obligations
- Good Industry Practice and Defects
- Digital by Default Standards
- Section 71
- The Basics Portal
- Section 73
- The Barring Portal
- Section 75
- Section 76
- Barring Portal: Loss of productivity - Item 11 of the Updated Schedule of Loss
- LPF Portal
- Siebel Useability Issues
- Redaction
- Document naming, bundle creation and performance
- Adobe Licence (Item 20)
- Document Storage (Item 21)
- Other B1 Barring Quality Issues
- Scan on Demand
- Special Characters
- Letters
- Item 24 : Loss of Efficiency Claims arising out of R1 Barring Quality/Useability Issues
- N-1 Sustainment Costs
- Causation and Loss
- Exit/Service Transfer
- Identification of all services (3.2.2)
- Knowledge Transfer (3.2.6 and 3.2.7)
- Section 95
- Providing all documentation to a replacement contractor (3.2.1 and 3.2.10)
- The identification of all leases, maintenance agreement and support agreements in connection with the provision of the services (3.2.3)
- Providing any other information or assistance reasonably required by a replacement contractor (3.2.14)
- Causation and Loss
- The Security Incidents
- The Charges Variation Dispute Introduction
- Issue 1: How the amount of an ‘over-recovery of the Forecast Revenue’ (Clause 2.8.4) or ‘under-recovery of the Forecast Revenue’ (Clause 2.8.5) is to be measured
- Section 104
- Issue 4: How Clause 2.8.5 of Schedule 2-3 applied to Volume Based Service Charges in Service Year 5
- Issue 2: Whether the Predicted Volumes for Basics in Service Year 4 were 1,000,000 (TCS’s case) or 320,374 (DBS’s case)
- Conclusion on Volume Based Service Charge
- Conclusions