![HT-2020-000448 - [2024] EWHC 1185 (TCC)](https://backend.juristeca.com/files/emisores/logo_yJUntHA.png){kind=logo}
The identification of all leases, maintenance agreement and support agreements in connection with the provision of the services (3.2.3)
The identification of all leases, maintenance agreement and support agreements in connection with the provision of the services (3.2.3)
This was not a specific complaint made in paragraph 106 of the Amended Defence and Counterclaim, and neither the experts nor the factual witnesses give any description of how DBS failed to comply with this obligation. In principle, this appears to be a similar complaint to the Master Document List. In the v09 spreadsheet DBS raised two comments. The first related to clarification that the transfer of documents was not to be held up if they did not happen all to be ready at the same time, which TCS accommodated. The second comment sought clarification within the STP about what information had already been identified. As TCS rightly responded, the obligation was for TCS to provide proposals as to how this information will be identified, not to identify it as part of the STP. TCS’s STP included the proposal for how it would be gathered and presented to DBS.
I find that STP v0.9 was not in breach of Clause 3.2.3 of Schedule 2-11.
- Heading
- CONTENTS
- IntroductiON
- The Factual Witnesses
- Expert Evidence
- Programming Experts
- Forensic Accounts
- The Parties Submissions
- Principles Applicable to Issues of Construction
- The Defendant’s Obligations and Responsibilities
- Clause 15
- Clause 9.5 which states
- Clause 14.5 of Schedule 2-6 which states
- The Delay and Notice Provisions
- Clause 7
- Conditions Precedent: Clauses 5 and 6
- Conditions Precedent: the authorities
- Clause 5.6
- Clause 6
- Clause 8
- Limitations of Liability
- A single or multiple caps?
- The Delay Damages cap under Clause 52.2.5
- Is TCS’s claim for loss of anticipated costs savings excluded by Clause 52?
- Compliance with Clause 5.3, Agreement and Estoppel Introduction
- Express Agreement
- Estoppel
- Introduction
- R1 B&B Delays
- Mr Britton’s First Analysis
- Mr Britton’s Second Analysis
- Conclusion on Mr Britton’s Analyses
- TCS’s submission based upon Mr Jardine’s analysis
- Responsibilities for Delay on the ‘Infrastructure’ Critical Path
- R1-D
- Compliance with Notice Provisions
- Analysis of Delays
- Up to August 2017
- From August 2017 to 19 September 2018
- Analysis
- Failed to confirm its desired functional scope of R1 Disclosure in relation to the Customer-to-Business portal and Accountable Officer’s Update Service functionality. Such confirmation was a prerequis
- Failed to make available an end-to-end test environment for the Interactive Voice Response system
- Failed to agree upon a data migration approach, without which the Claimant could not complete the build of a data migration environment so that anonymised data could be made available for testing
- Failed to ensure that relevant external stakeholders were available to participate in Final Systems Integration Testing
- Partial Termination
- TCS’s Claims
- Non-Manpower Costs
- Anticipated Cost Savings
- Summary of TCS’s Delay Claim Recovery
- DBS’s Claims
- Delay Payments
- R1-B&B Delay
- Disclosure Scotland Extension Costs – Item 1 of the Updated Schedule of Loss
- Loss of Anticipated Savings – Item 3 of the Updated Schedule of Loss
- R1-D Delay
- R0 Licence Costs – Item 4 of the Updated Schedule of Loss
- R0 Hosting and Infrastructure Costs - Item 5 of the Updated Schedule of Loss
- R0 Technology Refresh – Item 6 of the Updated Schedule of Loss
- R0 N-1 Sustainment Costs – Item 7 of the Updated Schedule of Loss
- R0 Maintenance Costs – Item 8 of the Updated Schedule of Loss
- Savings
- Introduction
- Quality-related Obligations
- Good Industry Practice and Defects
- Digital by Default Standards
- Section 71
- The Basics Portal
- Section 73
- The Barring Portal
- Section 75
- Section 76
- Barring Portal: Loss of productivity - Item 11 of the Updated Schedule of Loss
- LPF Portal
- Siebel Useability Issues
- Redaction
- Document naming, bundle creation and performance
- Adobe Licence (Item 20)
- Document Storage (Item 21)
- Other B1 Barring Quality Issues
- Scan on Demand
- Special Characters
- Letters
- Item 24 : Loss of Efficiency Claims arising out of R1 Barring Quality/Useability Issues
- N-1 Sustainment Costs
- Causation and Loss
- Exit/Service Transfer
- Identification of all services (3.2.2)
- Knowledge Transfer (3.2.6 and 3.2.7)
- Section 95
- Providing all documentation to a replacement contractor (3.2.1 and 3.2.10)
- The identification of all leases, maintenance agreement and support agreements in connection with the provision of the services (3.2.3)
- Providing any other information or assistance reasonably required by a replacement contractor (3.2.14)
- Causation and Loss
- The Security Incidents
- The Charges Variation Dispute Introduction
- Issue 1: How the amount of an ‘over-recovery of the Forecast Revenue’ (Clause 2.8.4) or ‘under-recovery of the Forecast Revenue’ (Clause 2.8.5) is to be measured
- Section 104
- Issue 4: How Clause 2.8.5 of Schedule 2-3 applied to Volume Based Service Charges in Service Year 5
- Issue 2: Whether the Predicted Volumes for Basics in Service Year 4 were 1,000,000 (TCS’s case) or 320,374 (DBS’s case)
- Conclusion on Volume Based Service Charge
- Conclusions