![HT-2020-000448 - [2024] EWHC 1185 (TCC)](https://backend.juristeca.com/files/emisores/logo_yJUntHA.png){kind=logo}
The Factual Witnesses
The Factual Witnesses
TCS called 12 witnesses of fact, 9 of whom gave live evidence. DBS called 22 witnesses of fact, 16 of whom gave live evidence. I do not set out an individual assessment of each factual witness. As would be entirely understandable in relation to events some five to seven years ago, most witnesses’ recollections were relatively vague and generalised when unprompted by contemporaneous written material. At times, of course, the answers of some witnesses were coloured by that individual’s own perception of where responsibilities lay for the problems which the project faced, and the evident lack of trust which existed between the two companies by the late stages of the relationship. Happily, however, I did not find any of the factual witnesses evasive or obtuse, and considered all were generally attempting to provide the Court with genuine assistance. Where appropriate in the context of specific issues, I identify where I have accepted, or rejected, particular aspects of a witness’s evidence. When considering the witness’s evidence I have had regard to their recollections as recorded in their witness statements and oral evidence alongside the contemporaneous correspondence and other written records, bearing in mind that whilst these are an extremely valuable source of evidence, they too can be the product of unconscious bias and unintentional fallibility and do not demand uncritical primacy (as set out in the extra-judicial speech by Popplewell LJ ‘Judging Truth from Memory: The Science’ (Footnote: 1)).
- Heading
- CONTENTS
- IntroductiON
- The Factual Witnesses
- Expert Evidence
- Programming Experts
- Forensic Accounts
- The Parties Submissions
- Principles Applicable to Issues of Construction
- The Defendant’s Obligations and Responsibilities
- Clause 15
- Clause 9.5 which states
- Clause 14.5 of Schedule 2-6 which states
- The Delay and Notice Provisions
- Clause 7
- Conditions Precedent: Clauses 5 and 6
- Conditions Precedent: the authorities
- Clause 5.6
- Clause 6
- Clause 8
- Limitations of Liability
- A single or multiple caps?
- The Delay Damages cap under Clause 52.2.5
- Is TCS’s claim for loss of anticipated costs savings excluded by Clause 52?
- Compliance with Clause 5.3, Agreement and Estoppel Introduction
- Express Agreement
- Estoppel
- Introduction
- R1 B&B Delays
- Mr Britton’s First Analysis
- Mr Britton’s Second Analysis
- Conclusion on Mr Britton’s Analyses
- TCS’s submission based upon Mr Jardine’s analysis
- Responsibilities for Delay on the ‘Infrastructure’ Critical Path
- R1-D
- Compliance with Notice Provisions
- Analysis of Delays
- Up to August 2017
- From August 2017 to 19 September 2018
- Analysis
- Failed to confirm its desired functional scope of R1 Disclosure in relation to the Customer-to-Business portal and Accountable Officer’s Update Service functionality. Such confirmation was a prerequis
- Failed to make available an end-to-end test environment for the Interactive Voice Response system
- Failed to agree upon a data migration approach, without which the Claimant could not complete the build of a data migration environment so that anonymised data could be made available for testing
- Failed to ensure that relevant external stakeholders were available to participate in Final Systems Integration Testing
- Partial Termination
- TCS’s Claims
- Non-Manpower Costs
- Anticipated Cost Savings
- Summary of TCS’s Delay Claim Recovery
- DBS’s Claims
- Delay Payments
- R1-B&B Delay
- Disclosure Scotland Extension Costs – Item 1 of the Updated Schedule of Loss
- Loss of Anticipated Savings – Item 3 of the Updated Schedule of Loss
- R1-D Delay
- R0 Licence Costs – Item 4 of the Updated Schedule of Loss
- R0 Hosting and Infrastructure Costs - Item 5 of the Updated Schedule of Loss
- R0 Technology Refresh – Item 6 of the Updated Schedule of Loss
- R0 N-1 Sustainment Costs – Item 7 of the Updated Schedule of Loss
- R0 Maintenance Costs – Item 8 of the Updated Schedule of Loss
- Savings
- Introduction
- Quality-related Obligations
- Good Industry Practice and Defects
- Digital by Default Standards
- Section 71
- The Basics Portal
- Section 73
- The Barring Portal
- Section 75
- Section 76
- Barring Portal: Loss of productivity - Item 11 of the Updated Schedule of Loss
- LPF Portal
- Siebel Useability Issues
- Redaction
- Document naming, bundle creation and performance
- Adobe Licence (Item 20)
- Document Storage (Item 21)
- Other B1 Barring Quality Issues
- Scan on Demand
- Special Characters
- Letters
- Item 24 : Loss of Efficiency Claims arising out of R1 Barring Quality/Useability Issues
- N-1 Sustainment Costs
- Causation and Loss
- Exit/Service Transfer
- Identification of all services (3.2.2)
- Knowledge Transfer (3.2.6 and 3.2.7)
- Section 95
- Providing all documentation to a replacement contractor (3.2.1 and 3.2.10)
- The identification of all leases, maintenance agreement and support agreements in connection with the provision of the services (3.2.3)
- Providing any other information or assistance reasonably required by a replacement contractor (3.2.14)
- Causation and Loss
- The Security Incidents
- The Charges Variation Dispute Introduction
- Issue 1: How the amount of an ‘over-recovery of the Forecast Revenue’ (Clause 2.8.4) or ‘under-recovery of the Forecast Revenue’ (Clause 2.8.5) is to be measured
- Section 104
- Issue 4: How Clause 2.8.5 of Schedule 2-3 applied to Volume Based Service Charges in Service Year 5
- Issue 2: Whether the Predicted Volumes for Basics in Service Year 4 were 1,000,000 (TCS’s case) or 320,374 (DBS’s case)
- Conclusion on Volume Based Service Charge
- Conclusions